NORTH MIDLAND BUILDING LTD v CYDEN HOMES LTD
[2018] BLR Plus 38
COURT OF APPEAL (CIVIL DIVISION)
Before Sir Terence Etherton, Master of The Rolls, Sir Ernest Ryder, Senior President of Tribunals, and Lord Justice Coulson
Acts of prevention - JCT Design and Build Contract 2005 - Extension of time - Concurrent delay caused by Contractor - Clause requiring such concurrent delays to be disregarded enforceable - Implied term preventing imposition of liquidated damages