LW INFRASTRUCTURE PTE LTD v LIM CHIN SAN CONTRACTORS PTE LTD
[2012] BLR Plus 3
HIGH COURT OF SINGAPORE
Judith Prakash J
Time at large - Liquidated damages - Delay to progress - No delay to completion caused by employer's breaches - Termination of sub-contractor's employment - Accrued rights to liquidated damages at termination - Whether liquidated or common law damages recoverable for period after termination - Contractual notice for liquidated damages