PROBUILD CONSTRUCTIONS (AUST) PTY LTD v DDI GROUP PTY LTD
[2018] BLR Plus 30
SUPREME COURT OF NEW SOUTH WALES COURT OF APPEAL
Before Beazley ACJ, McColl JA, and MacFarlan JA
Adjudication - Construction contract - Australia - Building and Construction Industry Security of Payment Act 1999 (NSW) - Set-off for liquidated damages - Entitlement to extension of time - Possible act of prevention - Scope of what was referred to adjudication - Breach of natural justice - Rough justice - Analysis of adjudication submissions on pragmatic non-legalistic basis.